SECOND AMENDMENT TO LEASE
THIS SECOND AMENDMENT TO LEASE (this ”Amendment“) is entered into as of this 06th day of January, 2021 (the “Effective Date“), by and between BMR-201 INDUSTRIAL ROAD LP, a Delaware limited partnership ("Landlord"), and NATERA, INC., a Delaware corporation ("Tenant").
RECITALS
AGREEMENT
NOW, THEREFORE, Landlord and Tenant, in consideration of the mutual promises contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, agree as follows:
BioMed Realty form dated 6/9/20
17129039.2
Dates | Square Feet of Rentable Area | Base Rent per Square Foot of Rentable Area | Monthly Base Rent | Annual Base Rent |
10/6/23 - 10/5/24 | 136,258 | $5.70 monthly | $776,670.60 | $9,320,047.20 |
| 2 | 17129039 |
from a third party (e.g., insurers, warrantors, or tortfeasors). Tenant shall have until the date which is eighteen (18) months after the Effective Date, as extended by Force Majeure (the "TI Deadline"), to submit Fund Requests (as defined in the Work Letter) to Landlord for disbursement of the unused portion of the TI Allowance, after which date Landlord's obligation to fund any such costs for which Tenant has not submitted a Fund Request to Landlord shall expire.
Natera, Inc.
201 Industrial Road, Suite 410 San Carlos, California 94070 Attention: Controller
| 3 | 17129039 |
With a copy to:Natera, Inc.
201 Industrial Road, Suite 410 San Carlos, California 94070 Attention: Legal Department
[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]
| 4 | 17129039 |
IN WITNESS WHEREOF, Landlord and Tenant have executed this Amendment as of the date and year first above written.
LANDLORD:
BMR-201 INDUSTRIAL ROAD LP,
a Delaware limited partnership
By: /s/ Kevin M. Simonsen
Name: Kevin M. Simonsen
Title:EVP, General Counsel & Secretary
TENANT:
NATERA, INC.,
a Delaware corporation
By: /s/ Steve Chapman
Name: Steve Chapman
Title: CEO
| | 17129039 |
EXHIBIT A
TENANT WORK LETTER
This Work Letter (this "Work Letter") is made and entered into as of the [06th] day of [January], 2021, by and between BMR-201 INDUSTRIAL ROAD LP, a Delaware limited partnership ("Landlord"), and NATERA, INC., a Delaware corporation ("Tenant"), and is attached to and made a part of that certain Second Amendment to Lease dated of even date herewith (the "Amendment" and together with the Original Lease and the First Amendment, as the same may be amended, amended and restated, supplemented or otherwise modified from time to time, the "Lease"), by and between Landlord and Tenant for certain Premises located at 201 Industrial Road in San Carlos, California. All capitalized terms used but not otherwise defined herein shall have the meanings given them in the Lease.
| 1. | General Requirements. |
| 1.1. | Authorized Representatives. |
EXHIBIT A
-1-
not be unreasonably withheld, conditioned or delayed. Such Schedule shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord disapproves the Schedule, then Landlord shall notify Tenant in writing of its objections to such Schedule, and the parties shall confer and negotiate in good faith to reach agreement on the Schedule. The Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as provided in this Work Letter.
EXHIBIT A
-2-
unreasonably withheld, conditioned or delayed. The Draft Schematic Plans shall contain sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Draft Schematic Plans whether Landlord approves or objects to the Draft Schematic Plans and of the manner, if any, in which the Draft Schematic Plans are unacceptable. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Draft Schematic Plans, then Tenant shall revise the Draft Schematic Plans and cause Landlord's objections to be remedied in the revised Draft Schematic Plans. Tenant shall then resubmit the revised Draft Schematic Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord's approval of or objection to revised Draft Schematic Plans and Tenant's correction of the same shall be in accordance with this Section until Landlord has approved the Draft Schematic Plans in writing or been deemed to have approved them. The iteration of the Draft Schematic Plans that is approved or deemed approved by Landlord without objection shall be referred to herein as the "Approved Schematic Plans."
EXHIBIT A
-3-
EXHIBIT A
-4-
carriers' requirements to Tenant) and the board of fire underwriters having jurisdiction over the Premises. The Tenant Improvements shall be deemed completed at such time as Tenant shall furnish to Landlord (t) evidence satisfactory to Landlord that (i) all Tenant Improvements have been completed and paid for in full (which shall be evidenced by the architect's certificate of completion and the general contractor's and each subcontractor's and material supplier's final unconditional waivers and releases of liens, each in a form acceptable to Landlord and complying with Applicable Laws, and a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect and the general contractor, together with a statutory notice of substantial completion from the general contractor), (ii) all Tenant Improvements have been accepted by Landlord, (iii) any and all liens related to the Tenant Improvements have either been discharged of record (by payment, bond, order of a court of competent jurisdiction or otherwise) or waived by the party filing such lien and (iv) no security interests relating to the Tenant Improvements are outstanding, (u) all certifications and approvals with respect to the Tenant Improvements that may be required from any Governmental Authority and any board of fire underwriters or similar body for the use and occupancy of the Premises (including a certificate of occupancy (or its substantial equivalent) for the Premises for the Permitted Use), (v) certificates of insurance required by the Lease to be purchased and maintained by Tenant, (w) an affidavit from Tenant's architect certifying that all work performed in, on or about the Premises is in accordance with the Approved Plans, (x) complete "as built" drawing print sets, project specifications and shop drawings and electronic CADD files on disc (showing the Tenant Improvements as an overlay on the Building "as built" plans (provided that Landlord provides the Building "as-built" plans provided to Tenant) of all contract documents for work performed by their architect and engineers in relation to the Tenant Improvements, (y) a commissioning report prepared by a licensed, qualified commissioning agent hired by Tenant and approved by Landlord for all new or affected mechanical, electrical and plumbing systems (which report Landlord may hire a licensed, qualified commissioning agent to peer review, and whose reasonable recommendations Tenant's commissioning agent shall perform and incorporate into a revised report) and (z) such other "close out" materials as Landlord reasonably requests at the time of Landlord's approval of the Construction Plans, consistent with Landlord's own requirements for its contractors, such as copies of manufacturers' warranties, operation and maintenance manuals and the like.
| 4. | Insurance. |
EXHIBIT A
-5-
forms a part of, or is contained in, the Tenant Improvements or any temporary structures on the Premises, or is adjacent thereto; provided that, for the avoidance of doubt, insurance coverage with respect to the general contractor's and any subcontractors' machinery, tools and equipment shall be carried on a primary basis by such general contractor or the applicable subcontractor(s). Tenant agrees to pay any deductible, and Landlord is not responsible for any deductible, for a claim under such insurance.
| 6. | TI Allowance. |
EXHIBIT A
-6-
(c) invoices from the general contractor, the architect, and any subcontractors, material suppliers and other parties requesting payment with respect to the amount of the TI Allowance then being requested, (d) unconditional lien releases from the general contractor and each subcontractor and material supplier with respect to previous payments made by either Landlord or Tenant for the Tenant Improvements in a form acceptable to Landlord and complying with Applicable Laws and (e) conditional lien releases from the general contractor and each subcontractor and material supplier with respect to the Tenant Improvements performed that correspond to the Fund Request each in a form acceptable to Landlord and complying with Applicable Laws, then Landlord shall, within thirty (30) days following receipt by Landlord of a Fund Request and the accompanying materials required by this Section, pay to (as elected by Landlord) the applicable contractors, subcontractors and material suppliers or Tenant (for reimbursement for payments made by Tenant to such contractors, subcontractors or material suppliers either prior to Landlord's approval of the Approved TI Budget or as a result of Tenant's decision to pay for the Tenant Improvements itself and later seek reimbursement from Landlord in the form of one lump sum payment in accordance with the Amendment and this Work Letter), the amount of Tenant Improvement costs set forth in such Fund Request or Landlord's pari passu share thereof if Excess TI Costs exist based on the Approved Budget; provided, however, that Landlord shall not be obligated to make any payments under this Section until the budget for the Tenant Improvements is approved in accordance with Section 6.2, and any Fund Request under this Section shall be submitted as of or prior to the TI Deadline and shall be subject to the payment limits set forth in Section 6.2 above and Section 7 of the Amendment. Notwithstanding anything in this Section to the contrary, Tenant shall not submit a Fund Request after the TI Deadline or more often than every thirty (30) days. Any additional Fund Requests submitted by Tenant after the TI Deadline or more often than every thirty (30) days shall be void and of no force or effect.
EXHIBIT A
-7-
design and other soft cost work that has been completed, (b) design and other soft costs spent through the end of the previous month, both from commencement of the Tenant Improvements and solely for the previous month, (c) the percentage of construction and other hard cost work that has been completed, (d) construction and other hard costs spent through the end of the previous month, both from commencement of the Tenant Improvements and solely for the previous month, and (e) the date of Substantial Completion of the applicable Tenant Improvements.
| 7. | Miscellaneous. |
[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]
EXHIBIT A
-8-
IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter to be effective on the date first above written.
LANDLORD:
BMR-201 INDUSTRIAL ROAD LP,
a Delaware limited partnership
By: /s/ Kevin M. Simonsen
Name: Kevin M. Simonsen
Title:EVP, General Counsel & Secretary
TENANT:
NATERA, INC.,
a Delaware corporation
By: /s/ Steve Chapman
Name: Steve Chapman
Title: CEO
EXHIBIT A
-9-